VIKAS MALHOTRA V. RAMPRASTHA ESTATES PVT. LTD.
Vikas Malhotra Vs. Ramprastha Estates Pvt. Ltd.
1. VIKAS MALHOTRA
B-96 Defense Colony,
Versus
1. RAMPRASTHA ESTATES PVT. LTD.
C-10, C-Block Market, Vasant Vihar,
Case No. : CONSUMER CASE NO. 1083 OF 2017
Date of Judgement : 04 December 2023
Judges : MR. SUBHASH CHANDRA
For Complainant : MR PRABHAT RANJAN, MR ASHRAY BHATIA,
MR ANKIT SEMAITI AND MR DROUHN GARG, ADVOCATES
For Opposite Party : MR SHIVENDRA DIWEVDI, MR ANKUR SETIA, ADVOCATES
Facts
- Complainant Vikas Malhotra booked a 300 sq yd plot in Ramprastha City project of OP Ramprastha Estates Pvt. Ltd. on 24.11.2011 for Rs 75 lakhs
- Rs 72 lakhs was paid against receipt no. 644 on 20.07.2012 (Rs 3 lakhs refunded from original amount)
- Despite several efforts, no plot was allotted even after 4 years and no communication received
- Complainant sought refund of amount paid with 18% interest compounded quarterly vide letter dated 22.03.2017
- No Plot Buyers Agreement executed, no date of possession given even after 6 years
Sections and Laws Referred
- Sec 21(a)(i) and Sec 22 of Consumer Protection Act 1986
- Supreme Court Judgments:
- Lucknow Development Authority v. M.K. Gupta
- Bangalore Development Authority v. Syndicate Bank
- Pioneer Urban Land v. Geetu Gidwani Verma
- Pioneer Urban Land v. Govindan Raghavan
- Kolkata West International City v. Devasis Rudra
- Experion Developers v. Sushma Ashok Shiroor
So in summary, the delay of over 6 years in offering possession or timeline was held as deficiency in service amounting to unfair trade practice, entitling the complainant to refund plus 9% interest p.a. as compensation, relying on various Supreme Court judgments.
Download Court Copy : https://dreamlaw.in/wp-content/uploads/2023/12/task-7-nitishu.pdf
Full text of Judgement :
1. This consumer complaint under section 21(a)(i) of the Consumer Protection Act, 1986 (in short, the ‘Act’) read with section 22 alleges unfair trade practice and deficiency in service in delay in handing over possession of a plot booked in a project promoted and executed by the opposite party within the promised time and seeking refund of the amount deposited with compensation and other costs.
2. The facts, according to the complainant, are that on 24.11.2011 he booked a plot admeasuring 300 sq yds in ‘Ramprastha City’, Sector 37D, Gurgaon by depositing Rs.72,00,000/- against receipt no 644 on 20.07.2012 (when Rs 3,00,000/- was refunded from the Rs 75,00,000/- deposited on 24.11.2011). After several efforts with the opposite party went in vain, the complainant informed the opposite party on 18.12.2015 that the plot had not been allotted nor any communication received even after passage of 4 years. Another reminder was sent on 22.03.2017 when refund with 18% interest compounded quarterly was sought. The complainant states that neither a Plot Buyers Agreement had been executed till date nor any date of handing over communicated by the opposite party till date. The complainant is before this Commission with the prayer to direct the opposite party to:
(vi) any other order deemed fit.
4. Parties led their evidence and filed rejoinder, affidavit, and evidence as well as short synopsis of arguments. I have heard the learned counsel for the parties and carefully considered the material on record.
5. On behalf of the complainant it was argued that the attempt of the opposite party to ascribe the delay to the concerned authorities cannot be accepted in view of the judgement of the Hon’ble Supreme Court in Lucknow Development Authority Vs. M. K. Gupta, (1994) 1
Ltd. Vs. Govindan Raghavan, CA No. 12238 of 2018 decided on 02.04.2019.
Haryana issued orders treating the period from the date of issue of licence till 01.09.2017 to be treated as ‘Zero Period’ as far as the obligation of the opposite party “qua dues and other concomitant approvals and charges appurtenant to this License”. It was, therefore, averred that there was no delay on part of the opposite party and hence no liability for deficiency in service or unfair trade practice.
7. From the foregoing it is an admitted fact that the complainant booked a plot in opposite party’s project, “Ramprastha City” on 24.11.2011. It is also evident that the opposite party was aware as early as 07.04.2014, when it applied for change of its layout plans, that the
project as promoted was likely to undergo changes in view of the necessity to modify the Sectoral Plans. It made several efforts to have revised plans approved in order to proceed but was able to get appropriate orders on 01.09.2017. Its efforts thereafter seem to have been
directed at getting an order for a “Zero Period” for the license which it succeeded in obtaining on 01.04.2021. There is no evidence brought on record to establish the efforts the opposite party made to keep the complainant in the knowledge of the developments with regard to the Sectoral Plans or the likely scenario or developments. No evidence has been brought on the record to indicate that the complainant was either offered the option to continue with the scheme or to opt out which the opposite party should have done considering it had accepted full sale consideration in 2011. No evidence is brought on record to indicate the steps taken till 23.12.2016 to expedite the matter. No Plot Buyers Agreement was proposed in the matter even after over 5 years of the receipt of funds. The action of the opposite party to keep the complainant completely in the dark without any alternative options after receiving the entire sale consideration is clearly an unfair trade practice. Irrespective of the issues with the Sectoral Plans and the Licence, it was incumbent upon the opposite party to share details and likely timelines with the opposite party whose funds it had accepted. Without entering into an agreement that would have defined the rights and obligations of both parties which would have enabled a decision to either continue or exit the scheme, the opposite party kept the funds collected without any progress on the project. The action of the opposite party in not entering into an agreement precluded this opportunity for the complainant. This is manifestly an abuse of dominant position and an unfair trade practice.
8. The inaction of the opposite party to even propose a Plot Buyers Agreement failed to set out a possible timeline for the complainant as a consumer. However, considering the complaint was filed in 18.04.2017 the delay of 6 years cannot be considered reasonable by any yardstick. Even as on date, after the revision of the Sectoral Plans for sectors 37 C and D as on 01.09.2017, as stated by the opposite party, there is no layout plan approval. The delay in handing over of possession, even if reckoned from this date, is nearly 6 years. The delay
Planning Department.
9. The averment of the opposite party that the delay was due to factors beyond its control cannot be sustained in view of the fact that the scheme should have been redesigned in the light of the approvals available and a revised costing and payment plan proposed to the
argument that the delay was covered by any force majeure condition cannot be considered also because there was no agreement in place under which such conditions could be formally decided.
10. In the instant case, there is neither an offer of possession nor a likely date by when possession can be offered. The contentions of the opposite party are tantamount to requiring the complainant to wait indefinitely for possession of the plot booked in 2011. This is both
Appeal No. 12238 of 2018 with No. 1677 of 2019 dated 02.04.2019 and in Pioneer Urban land and Infrastructure Ltd., vs Govindan Raghavan in Civil Appeal no. 12238 of 2018 decided on 02.04.2019 (2019) 5 SCC 725 that a buyer cannot be compelled to take possession of a flat when there is delay in delivery of possession by the builder and the buyer is obliged to refund along with compensation or interest for such delay. It has also held in Kolkata West International City Pvt. Ltd. Vs. Devasis Rudra, Civil Appeal No. 3182 of 2019 decided on 25.03.2019 regarding the right of the consumer to seek refund in view of the inordinate delay on the part of the opposite party. In Experion Developers Pvt. Ltd. Vs. Sushma Ashok Shiroor, C.A. No. 6044 of 2019 decided on 07.04.2022 the Hon’ble Supreme Court has held the compensation by way of interest has to be both compensatory as well as restitutionary and held that interest @ 9% would be fair and just. Compensation on the same lines will be appropriate in this matter also.
11. For the aforesaid reasons, in the facts and circumstances of this case, there is merit in the complaint and the same is liable to succeed. Accordingly, this complaint is allowed in part and disposed of with the following directions:
(iv) opposite party shall also pay the complainant litigation cost of Rs 50,000/-.
All pending IAs shall stand disposed of with this order.