EMAAR MGF LAND LTD. V. CHITERLEKHA JINDAL & 3 ORS.

Builder Company:

Interest rate of 10% is high, willing to offer 9% interest p.a only. Penal interest of 3% and interest of 12% on compensation amount not acceptable.

Complainants:

Awarded 10% Interest is fair, equitably compensates for troubles faced in 17 year period. Penal interest acts as deterrent for delayed payment, justified due to non-payment by builder company. Entire award by State Commission is logical and requires no interference.

Sections:
No sections have been cited.

Referred Laws:

Appeal filed under Section 19 of Consumer Protection Act, 1986. Reference made to execution and penalty proceedings under the Consumer Protection Act in case of default in payment.

Download Court Copy: https://dreamlaw.in/wp-content/uploads/2024/02/116.pdf

Full Text of Judgment:

1. This appeal has been filed under Section 19 of The Consumer Protection Act, 1986 in challenge to the Order dated 06.01.2020 of the State Commission in complaint no. 127 of 2019.
2. We have heard the learned counsel for the appellants (the ‘builder co.’) and the learned counsel for the respondents (the ‘complainants’). We have also perused the material on record, including inter alia the State Commission’s impugned Order dated 06.01.2020 and the memorandum of appeal.
3. The appeal has been filed with self-admitted delay of 113 days. However, in the interest of justice, inter alia considering the reasons mentioned in the application for condonation of delay, in order to provide fair opportunity to the builder co., to decide the matter on merit rather than to dismiss it on the threshold of limitation, the delay in filing the appeal is condoned.
4. The matter relates to a builder-buyer dispute.
Briefly, the builder co. entered into an agreement with the complainants on 19.06.2007 in respect of a residential plot. The complainants paid an amount of Rs. 38,21,650/- to the builder co. in the period from 23.09.2006 to 28.02.2014. The assured date for delivery of possession of the subject plot was two years from the date of execution of the agreement but not later than three years, that is to say, the agreement also provided for a grace period of one year beyond the said two year period. Counting from the date of the agreement, the assured two year period for completion of the project and delivery of possession of the plot elapsed on 18.06.2009 and the subsequent grace period of one year elapsed on 18.06.2010. The project was not completed and delivery of possession of the unit was not made within the assured period of two years, or even in the subsequent one year grace period, or even still within a reasonable period beyond (reasonable period here would connote a period which appears reasonable per se and which a reasonable man of ordinary prudence would not normally agitate). The complainants went before the State Commission on 16.05.2019 i.e. 9 years 10 months 28 days after the expiry of the assured period of two years and 8 years 10 months 28 days after the expiry of the grace period of one year. Inter alia considering the abnormal unreasonable delay in completing the project and making delivery of possession, the State Commission ordered the builder co. to refund the amount of Rs. 38,21,650/- deposited by the complainants with interest at the rate of 10% per annum from the respective dates of deposit within 30 days from the date of receipt of a certified copy of its Order failing which the said amount of Rs. 38,21,650/- shall carry additional penal interest at the rate of 3% per annum from the date of its Order. It also awarded lumpsum Rs. 50,000/- for causing mental agony and physical harassment, deficiency in service and unfair trade practice, and also towards cost of litigation, payable within 30 days from the date of receipt of a certified copy of its Order failing which the said amount of Rs. 50,000/- shall carry interest at the rate of 12% per annum from the date of its Order.
The award made by the State Commission as contained in para 17 of its impugned Order of 06.01.2020 is reproduced below for reference:
17. For the reasons recorded above, this complaint is partly accepted with costs and the opposite parties, jointly and severally, are directed as under:-
i) To refund the amount of Rs.38,21,650/- to the complainants, alongwith interest @10% p.a. (as prayed), from the respective dates of deposit onwards, within a period of 30 days, from the date of receipt of a certified copy of this order, failing which, thereafter, the said amount of Rs.38,21,650/- shall carry 3% penal interest i.e. 13% p.a. (10% p.a. plus (+) 3% p.a.), from the
date of passing of this order, till realization.
5. A perusal of the State Commission’s Order of 06.01.2020 shows that it is a well-appraised and reasoned order that has extensively dealt with the issues germane to the dispute.
7. In the present case, the assured period for completion of the project was two years from the date of the agreement along with a grace period of one year. The assured period expired on 18.06.2009. The subsequent one year grace period expired on 18.06.2010. The complaint was filed much afterwards on 16.05.2019. The State Commission decided the case on 06.01.2020. Even till then the completion certificate had not been obtained. It goes without saying that in the absence of the completion certificate it was most obviously not feasible to offer legitimately meaningful possession. On the face of it itself, abnormal unreasonable delay is patently manifest.
8. It may be observed that the grace period provided for in the agreement, by its very nature, is in itself an extended period for completion. That is to say, it itself provides to take care of some delay in completion. The material significance of the grace period needs to be understood in perspective. It by itself provides for a certain period of delay beyond the assured period and it is ab initio in-built into the agreement with the ‘consumer’. As such any period beyond the grace period has to be fully justifiable and tenable with cogent and convincing reasons, which is not at all the case here.
9. It is a well settled position that in case of abnormal, unreasonable and unjustified delay beyond the assured period two parallel rights accrue to the consumer: one :possession of the subject unit, if and when the subject unit is duly constructed and developed, along with just and equitable compensation under the Act 1986 / 2019 for the delay. or two :refund of the amount deposited along with just and equitable compensation. In the instant case the complainants have opted for refund of their deposited amount.
10. Learned counsel for the builder co. argues that the rate of interest of 10% per annum on the deposited amount is on the higher side. He submits that he has instructions to offer a rate of interest of 9% per annum only. He also submits that the added penal interest of 3% per annum for not making timely payment is not acceptable to the builder co. Similarly the interest of 12% per annum on the lumpsum amount of Rs. 50,000/- in case of delay in payment is also not acceptable. Submission is that the builder co. is agreeable to refund the deposited amount with interest at the rate of 9% per annum as well as to pay the lumpsum amount of Rs. 50,000/- without interest, anything more is not acceptable to it.
11. Learned counsel for the complainants submits that the rate of interest of 10% per annum awarded on the deposited amount is in every manner fair and equitable. He dwells over the protracted troubles and travails from 2006 onwards, when the complainants first made their deposits, till today, i.e. for about 17 years now. He submits that the penal interest of 3% per annum from the date of the State Commission’s Order was to act as a deterrent against not making timely payment and is quite reasonable per se and further that since the builder co. did not make timely payment the penal interest is fully justified. He makes similar submission in respect of the interest of 12% per annum from the date of the State Commission’s Order in the contingency of delay in making payment of the lumpsum amount of Rs. 50,000/-. Submission is that the award in its entirety has been logically and rationally moulded by the State Commission and requires no interference.
12. Regarding the compensation, we may first observe that in various situations where the consumer is not given a fair deal and where he is made to suffer by the service provider by being deficient in service or by resorting to some unfair trade practice, the eventuality of such plight has been adequately taken care of by the legislation and in order to redress his grievance statutory provisions have been enacted. Sections 14 of the Act 1986 contemplates to provide compensation for the loss or injury that may be suffered by such consumer and grant even punitive damages in appropriate cases where it is deemed fit. The legislature in its wisdom has not laid down any specific method fixed in nature or any specific manner in which the loss or injury suffered by a
13. Reverting to the facts of the case at hand, it is noted that the complainants had deposited total Rs.38,21,650/- with the builder co. between 23.09.2006 to 28.02.2014. The assured period of delivery of possession of the subject unit elapsed in June 2009. The builder co. did not deliver possession of the subject unit within the assured period, or even within the grace period of one year thence, or even still within a reasonable period thereafter. Even till the date on which the State Commission passed its Order i.e. 06.01.2020 the completion certificate had not been obtained, without which legitimate meaningful possession could not have been offered. Abnormally unreasonable and inordinate delay is self-evident. The afore contextual backdrop encapsulates the jeopardy to which the complainant has been put to, the uncertainty and difficulty he has faced, the mental agony and physical harassment he has suffered, the pecuniary loss to which he has been subjected to, and the cumulative injury which he has endured as a result of all this. Pertinently, in the arguments on its behalf today, the ‘deficiency in service’ and ‘unfair trade practice’ per se, as have been categorically determined by the State Commission, are not being contested and the arguments are essentially aimed at getting the rate of the compensatory interest reduced.
14. It goes without saying that the compensation has to be just and equitable, commensurate with the loss and injury suffered. In the particular facts and circumstances of the present case it is felt that rate of interest of 10% per annum on the deposited amount, as awarded by the State Commission, is in every way just and equitable, commensurate with the loss and injury suffered by the complainants. Providing for 3% penal interest from the date of its Order also appears reasonable and has self-evidently factored-in the expedient need to ensure timely compliance. The objective it aims to subserve is obviously to at least now put an end to the long drawn troubles and travails of the complainants, to put a period to their sufferings. A bonafide builder co. could as well have refunded atleast the principal amount deposited by the complainants while retaining its right to agitate its issues and contentions regarding compensatory interest in a higher forum, or it could have made payment with interest at the rate of 9% per annum to which it is today agreeable and only challenged the rate over and above 9% and the penal interest of 3% per annum. And there should not have been much quarrel to pay the lumpsum amount of Rs. 50,000/- without interest in a time-bound manner. But it rather further delayed the matter by filing an appeal in which there is hardly anything to argue on the substance per se. As such, in the present case, in its specific facts and circumstances, we do not find any good reason to take a different view on the compensation than what has been taken by the State Commission.
15. The appeal, being bereft of worth, is dismissed.
The award made by the State Commission is confirmed.
The amount if any deposited by the builder co. before the State Commission shall be forthwith released by the State Commission to the complainants as per the due procedure.
The balance awarded amount as any shall be made good by the builder co. within six weeks from today, failing which the State Commission shall undertake execution, for ‘enforcement’ and for ‘penalty’, as per the law.
16. The Registry is requested to send a copy each of this Order to the parties in the appeal and to their learned counsel as well as to the State Commission immediately. The stenographer is also requested to upload this Order on the website of this Commission immediately.